HomeMy WebLinkAbout6.f. WSB Engineering Contract Renewal ROSEN4EIUI\JT
EXECUTIVE SUMMARY
CITY COUNCIL
City Council Regular Session: December 4, 2012
AGENDA ITEM: WSB Engineering Contract Renewal GENDA SECTION:
MU,catf
PREPARED BY: Dwight Johnson, City Administrator AGENDA NO. 1 :(".
ATTACHMENTS: Proposed Contract APPROVED BY:
Ott)
RECOMMENDED ACTION: Motion to approve the attached agreement with
WSB and Associates, Inc. for the years 2013-2015.
BACKGROUND
At the November 14th work session, the Council reviewed a draft agreement for City Engineering services
and indicated interest in renewing our contract with WSB Engineering. Accordingly, a draft contract for
the years 2013-2015 is attached for your consideration.
DISCUSSION
The draft agreement is for three years. Many of the terms of the proposed new agreement are the same,
but there are new provisions for obtaining an optional second opinion or value engineering on large,
complex projects.
WSB sought some new legal language to limit their liability when they are acting as our City Engineer. The
City's insurance carrier, the League of Minnesota Cities Insurance Trust (LMCIT), reviewed the new
language and raised a number of concerns. Accordingly, the new language on liability has been removed in
this final draft.
Finally, the retainer for the services of Andy Brotzler as our full time City Engineer/Director of Public
Works is proposed to increase from the current amount of$40,000 to $50,000 annually in 2013, $60,000 in
2014, and then increase by 4.16% to $62,500 in 2015. This increase has been expected based upon
conversations earlier this year with WSB and the current relatively low volume of business since the
recession began.
RECOMMENDATION
Staff supports the draft agreement as written and recommends that the agreement with WSB Engineering
for the years 2013-2015 be approved.
PROFESSIONAL SERVICES AGREEMENT
This Agreement is made as of the 1st day of January, 2013 by and between the City of
Rosemount, Minnesota, a Minnesota municipal corporation (hereinafter referred to as "City") and
WSB & Associates, Inc., a Minnesota corporation (hereinafter referred to as `Engineer") with
offices located at 701 Xenia Avenue South, Suite 300,Minneapolis, Minnesota 55416.
WITNESSETH:
That the City and Engineer, for the consideration herein named,agree as follows:
Section 1. Scope of Work. Engineer will provide services as described on Exhibit 1,
attached hereto and hereby made a part hereof(hereinafter generally referred to as the"Project"),on
a fixed monthly retainer payable in the month following the month in which services are rendered.
The monthly retainer will be$4166.67 for 2013, $5000 for 2014 and $5208.33 for 2015. These
services generally include administrative and staff duties as acting city engineer and director of
public works for the City. Work on the Project will generally be performed by Andy Brotzler or
another mutually agreeable employee of Engineer (the "Director of Public Works/City Engineer").
The cost of the work for development related projects is to be passed through to a developer or other
private party at the billing specified on Exhibit 2. Work requested by the City and performed by
other employees of Engineer that does not fall within the scope of services described on Exhibit 1
will be compensated on a hourly basis on the fee schedule attached hereto as Exhibit 2, or will be
made the subject of a separate contract for services.
All Services provided on behalf of the City per the agreed upon retainer shall be provided by
Engineer in its capacity as City Engineer/Director of Public Works. In this regard, the City agrees
that Engineer and its Employees have been requested to act as the agent of the City, a Municipality
- ! - - - - -
functions otherwise agreed upon. Engineer's actions on behalf of the City are deemed and agreed to
be the acts of a person who is in the paid service of the governmental entity. In this regard, Engineer
is not acting as an independent contractor, and instead is solely on behalf of the City which is
seeking to ensure the life,health, and well being of its citizens and the public in general.
Section 2. Changed Conditions. If the Engineer determines that any services it has been
directed or requested to perform are beyond the scope of services as set forth in Exhibit 1, Engineer
shall promptly notify the City of that fact. Additional work and additional compensation for such
work must have the prior approval of City.
Section 3. Term and Termination. Unless earlier terminated in accordance with this
paragraph,the term of this Agreement shall be three years from January 1, 2013 through December
31, 2015. This Agreement may be terminated by the City with no prior notice for malfeasance or
misconduct by Engineer. This Agreement may be terminated by either party upon ten days' notice
for material breach of this Agreement by the other party. This Agreement may be terminated by
either party upon ninety days' written notice without cause. In the event of termination, copies of
414887v42 CLL R5215-3 1
plans, reports, specifications, electronic drawing/data files (CADD), field data, notes, and other
documents whether written, printed or recorded on any medium whatsoever, finished or unfinished,
prepared by the Engineer pursuant to this Agreement and pertaining to the Project (hereinafter
"Instruments of Service"), shall be made available to the City subject to Section 4. All provisions of
this Agreement allocating responsibility or liability between the City and Engineer shall survive the
completion of the services hereunder and/or the termination of this Agreement.
Section 4. Reuse and Disposition of Instruments of Service. During the course of the work,
the Engineer shall, if requested, make available to the City copies of the Instruments of Service. At
the time of completion or termination of the work, the Engineer may make available to the City
copies of Instruments of Service upon (i) payment of amounts due and owing for work performed
and expense incurred to the date and time of termination,and(ii) fulfillment of the City's obligation
under this Agreement. Any use or re-use of such Instruments of Service by the City or others
without written verification or adaptation by the Engineer except for the specific purpose intended
will be at the City's risk and full legal responsibility.
Section 5. Agreement. The Agreement constitutes the entire understanding between the
Engineer and City. The Agreement supersedes all prior written or oral understanding and may only
be amended, supplemented,modified or canceled by a duly executed written instrument.
Section 6. Responsibilities. In order to permit the Engineer to perform the services required
under this Agreement, the City shall, in proper time and sequence and where appropriate to the
Project,at no expense to the Engineer:
1. Provide available information as to its requirements for the Project.
2. Guarantee access to and make all provisions for the Engineer to enter upon public and
private lands to enable the Engineer to perform its work under this Agreement.
3. Provide such legal, accounting and insurance counseling services as may be required for this
Project (such as review of insurance certificates, bonding clarifications and legal questions
regarding property acquisition or assessment).
4. Notify the Engineer whenever the City observes or otherwise becomes aware of any defect
in the Project.
5. Designate a person to act as City's representative with respect to the services to be rendered
under this Agreement. The City's representative shall have the authority to transmit and
receive instruction and information and to interpret and define the City's policies with
respect to services rendered by the Engineer.
6. Furnish data(and professional interpretations thereof)prepared by or services performed by
others, including where applicable, but not limited to, previous reports, core borings,
probings and sub-surface explorations,hydrographic and hydro geologic surveys, laboratory
tests and inspection of samples, materials and equipment; appropriate professional
interpretations of the foregoing data; environmental assessment and impact statements;
414887v42 CLL RS215-3 2
property, boundary, easement, right-of-way, topographic and utility surveys; property
description; zoning,deed and other land use restrictions; and other special data.
7. Review all reports, sketches, drawings, specifications and other documents prepared and
presented by the Engineer, obtain advice of legal, accounting and insurance counselors or
others as City deems necessary for such examinations and render in writing decisions
pertaining thereto within reasonable times so as not to delay the performance by the
Engineer of the services to be rendered pursuant to this Agreement.
8. Where appropriate, endeavor to identify, remove and/or encapsulate asbestos products or
materials or pollutants located in the project area prior to accomplishment by the Engineer
of any work on the Project.
9. Provide record drawings and specifications for all existing physical plants of facilities that
are pertinent to the Project.
10. Where available provide other services,materials,or data.
11. Bear all costs incidental to compliance with the requirements of this Section.
12. Provide the foregoing in a manner sufficiently timely so as not to delay the performance by
the Engineer of the services in accordance with this Agreement.
From time to time developers, owners or third parties may provide the City with surveys, plats,
drainage plans, utility drawings, engineering or architectural drawings or other materials prepared
by third party professionals. Engineer shall have no responsibility or liability to the City or third
parties for the accuracy or sufficiency of documentation prepared by those outside design
professionals. Engineer will notify the City of errors, discrepancies and inconsistencies it may
discover in such documents. In the event Engineer reviews documents for code compliance,
performs constructability reviews, value-engineering or any other reviews or tasks involving the
design of third parties provided to the City, it is understood that such reviews will not render
Engineer liable in any manner for the duties of separately-retained design professionals
Engineer shall be entitled to rely on the accuracy and completeness of information or services
furnished by the City or by others employed or retained by the City. Engineer shall be entitled to
rely on information furnished by third parties to the City or Engineer. Engineer shall endeavor to
verify the information provided and shall promptly notify the City if the Engineer discovers that any
information or services furnished by the City,or provided or furnished by third parties to the City,is
in error or is inadequate for its purpose but is not liable for errors in material provided by the City or
third parties.
Section 7. Opinions of Cost. Opinion, if any, of probable cost, construction cost, financial
evaluations, feasibility studies, economic analyses of alternate solutions and utilitarian
considerations of operations and maintenance costs are made or to be made on the basis of the
Engineer's experience and qualifications and represent the Engineer's best judgment as an
experienced and qualified professional design firm. The parties acknowledge, however, that the
414887v42 CLL RS215-3 3
Engineer does not have control over the cost of labor, material, equipment or services furnished by
others or over market conditions or Engineer's methods of determining their prices, and any
evaluation of any facility to be constructed or acquired, or work of necessity must be speculative
until completion of construction or acquisition. Accordingly, the Engineer does not guarantee that
proposals, bids or actual costs will not vary from opinions, evaluations or studies submitted by the
Engineer. .. . - _ • - _ -- . :The City may obtain value engineering
recommendations or a second opinion on complex or expensive projects. Engineer agrees to assist
the City in the selection of a consultant or adjoining public agency staff engineer to provide these
services if requested to do so. The value engineering or second opinion will consist of an evaluation
of recommendations provided by the Engineer. The City and Engineer will work together to
evaluate the recommendations.
Section 8. Hold Harmless and Insurance. In serving in the capacity of Director of Public
Works/City Engineer, Engineer will provide its services intended to satisfy the City's obligations to
the public. In no instance will the engineer's duty or liability to the public or any individual
claimant be greater than that of the City.
The City agrees to secure liability insurance for the City Engineer/Director of Public Works
for services provided under this Agreement on behalf of the City, so long as services are provided
by the Engineer in good faith and at the direction of the City. The City agrees that the Engineer
shall be considered an agent of the City with respect to any and all claims that relate in any way to
the services provided by Engineer in its capacity as Director or Pub '
Sections 166.01 et seq. Engineer has procured insurance in the types and amounts set forth in
Exhibit 3.
The Engineer agrees to indemnify and hold harmless the City, its officers and employees,
from any liabilities, claims, damages, costs, judgments, and expenses, including attorney's fees,
resulting directly or indirectly from an act of omission of the Engineer, its employees, agents or
employees of consultants, in the performance of this contract of by reason of the failure of the
Engineer to fully perform, in any respect,all of its obligations under this contract.
The City acknowledges that professional liability (errors and omissions) insurance is
unavailable to cover claims arising out of the performance or failure to perform professional
services, including, but not limited to, the preparation of reports, designs, drawings and
specifications related to the investigation, detection, abatement, replacement, modification, removal
or disposal of:
1. Hazardous or toxic materials; or
2. Materials or processes containing asbestos.
As used herein, hazardous or toxic materials shall include but not be limited to any solid,
liquid, gaseous or thermal irritant, contaminant, or hazardous waste as defined by Federal and State
Law and cases construing such definition. Waste includes materials to be recycled,reconditioned or
reclaimed. It is acknowledged by both parties that Engineer's scope of services does not include
any services related to asbestos or hazardous or toxic materials. In the event the Engineer or any
414887v42 CLL R5215-3 4
other party encounters asbestos or hazardous or toxic materials at the job site, or should it become
known in any way that such materials may be present at the job site or any adjacent areas that may
affect the performance of the Engineer's services, the Engineer may, at its option and without
liability for consequential or any other damages, suspend performance of services on the project
until the City retains appropriate specialist consultant(s) or contractor(s) to identify, abate and/or
remove the asbestos or hazardous or toxic materials, and warrant the job site is in full compliance
with applicable laws and regulations.
Section 9. Assignment. This Agreement, intended to secure the service of individuals
employed by and through the Engineer, shall not be assigned or transferred without written consent
of the City.
Section 10. Controlling Law. This Agreement is to be governed by the laws of the State of
Minnesota.
Section 11. Non-Discrimination. Engineer will comply with the provisions of applicable
Federal, State and Local Statutes, Ordinances and Regulations pertaining to human rights and non-
discrimination.
Section 12. Conflict Resolution. In an effort to resolve any conflicts that arise during the
design or construction of the project or following the completion of the project, the City and
Engineer agree that all disputes between them arising out of or relating to this Agreement shall be
submitted to nonbinding mediation unless the parties mutually agree otherwise.
Section 13. Attorney's Fees. In the event of any litigation arising from or related to the
services provided under this Agreement, the prevailing party will be entitled to recovery of all
reasonable costs incurred, including staff time, court costs, attorneys' fees and other related
expenses.
Section 14. Confidentiality. The Engineer agrees to keep confidential and not to disclose to
any person or entity, other than the Engineer's employees, subconsultants and the general contractor
and subcontractors, if appropriate, any data and information not previously known to and generated
by the Engineer or furnished to the Engineer and marked CONFIDENTIAL by the City and to
comply with the provisions of the Minnesota Government Data Practices Act, Minn. Stat. Ch. 15.
These provisions shall not restrict the Engineer from giving notices required by law or complying
with an order to provide information or data when such order is issued by a court, administrative
agency or other authority with proper jurisdiction,or if it is reasonably necessary for the Engineer to
defend itself from any suit or claim.
Section 15. Location of Underground Improvements. The Engineer will conduct the
research that in its professional opinion is necessary and will prepare a plan indicating the locations
intended for subsurface penetrations with respect to assumed locations of underground
improvements. Such services by the Engineer will be performed in a manner consistent with the
ordinary standard of care. The City recognizes that the research may not identify all underground
improvements and that the information upon which the Engineer relies may contain errors or may
not be completed.
414887v42 CLL R5215-3 5
Section 16. Betterment. If, due to the Engineer's error, any required item or component of
the project is omitted from the Engineer's construction documents, the Engineer shall not be
responsible for paying the cost to add such item or component to the extent that such item or
component would have been otherwise necessary to the project or otherwise adds value or
betterment to the project. The Engineer shall be responsible for the difference between the
construction cost arrived at through the bid process and the construction cost actually negotiated, if
there is a difference. This amount will be negotiated between the City and Engineer.
Section 17. Engineer Status. In the performance of all services under this Agreement,
Engineer shall be an ' 'n1 cOntractor and not-be an employee of the City and neither the
Acting Director of Public Works/City Engineer nor any other officer, employee or agent of
Engineer shall be an employee of the City for any purpose whatsoever.
WSB &ASSOCIATES,INC.
By
Its
CITY OF ROSEMOUNT
By
Its Mayor
And By
Its Clerk
414887v42 CLL RS215-3 6
EXHIBIT 1
RETAINER SERVICES
THE PROJECT
General Director of Public Works and City Engineering Duties:
1. Acts in a department head capacity for the Public Works Department including planning,
coordinating, supervising and evaluating programs, plans, services, staffing, equipment,
infrastructure and maintenance.
2. Evaluates public works needs and formulates short and long range plans to meet needs in
all areas of responsibility, including streets, water, sewer, drainage, light, park
maintenance, building maintenance, vehicle and equipment for the City.
3. Meets with developer and members of the public on proposed development projects in order
to relate the processes and procedures involved with engineering and infrastructure
development. Ensures that costs and fees are charged back to development projects; works
with the Finance Department to monitor charges and revenues associated with development
projects.
4. Determines the need for preliminary studies; reviews all preliminary studies for compliance
with ordinances,comprehensive plans,engineering standards and financial guidelines.
5. Directs engineering activities on projects; oversees project management for the construction
of the municipal public works projects.
6. Regularly attends City meetings including City Council and Utility Commission meetings,
and on an as-needed basis,City Council Work Session and Planning Commission meetings.
7. Directs the assessment process for recovery of municipal costs incurred on improvement
projects.
8. Develops systems to monitor sewer and water usage; compiles data designed to annually
update the sewer and water rate study; directs the preparation of reports for the Metropolitan
Waste Control Commission.
9. Prepares annual departmental budgets and monitors expenditures.
10. Acts as city liaison and city representative with other communities and county, state and
federal agencies.
1-1
414887v-1-2 CLL RS215-3
11. Provides advice and recommendations to the City Administrator and other city department
heads and staff; reviews proposals submitted by management staff and makes appropriate
comments and suggestions; and assists city staff with any engineering needs.
12. Works with consultants and other outside individuals/groups involved in studies affecting
city services and coordinates special projects and studies.
13. Develops and implements policies and procedures for effective operation of the department
consistent with city policies and relevant laws, rules and regulations and ensures council
actions are implemented.
14. Oversees the preparation and updating of the city's plans such as the Storm Water
Management Plan, Water Supply & Distribution Plan, Wetland Management Plan, etc;
develops, updates and oversees the public works capital improvement plan; develops and
revises city policies for storm water,assessments and other areas as required.
15. Oversees the maintenance of the city's Municipal State Aid Road System.
16. Makes public presentations and deals with the public on an individual basis.
17. Supervises staff either directly or through subordinate supervisors and oversees operations
to assure the desired level and quality of service is being provided. Supervision of staff
includes: assignments, direction, discipline, suspension, reward, adjust grievances, transfer
of employees and recommends the hiring, discharge or promotion of employees in the
Public Works Department.
1-2
414887v�2 CLL RS215-3
EXHIBIT 2
RATE SCHEDULE (Insert 2013 Rate Schedule)
Billing
Rate/Hour
Principal $134.00
Associate $126.00
Sr.Project Manager/Sr.Project Engineer $121.00
Project Manager II/Project Engineer III/Engineering Specialist IV $112.00
Project Manager/Project Engineer II/Engineering Specialist III $105.00
Project Engineer/Registered Land Surveyor/Engineering Specialist II $96.00
Graduate Engineer II/Engineering Specialist I/Sr.Construction Observer $86.00
Graduate Engineer/Engineering Technician V/Construction Observer $76.00
Engineering Technician IV/Scientist III $68.00
Engineering Technician III/Scientist II $62.00
Engineering Technician II/Scientist I $56.00
Engineering Technician I $49.00
Office Technician II $62.00
Office Technician I $33.00
Survey(Two-Person Crew/GPS Crew) $140.00
Survey(Three-Person Crew/Expanded GPS Crew) $167.00
Costs associated with word processing,vehicle mileage,cell phones,reproduction of common
correspondence and mailing are included in the above hourly rates.
Reimbursable expenses include costs associated with plan,specification and report reproduction,
permit fee,delivery cost,etc.
Rate Schedule is adjusted annually.
2-1
414887v+2 CLL RS215-3
EXHIBIT 3
INSURANCE
This contract shall be effective only upon the approval by the City of acceptable evidence of the
insurance detailed below. Such insurance secured by the Engineer shall be issued by insurance
companies acceptable to the City and admitted in Minnesota. The insurance specified may be in
a policy or policies of insurance, primary or excess. Such insurance shall be in force on the date
of execution of the contract and shall remain continuously in force for the duration of the
contract.
The Engineer and its contractors shall secure and maintain the following insurance:
a. Worker's Compensation insurance that meets the statutory obligations with Coverage B -
Employer's Liability limits of at least $100,000 each accident, $500,000 disease -policy limit
and $100,000 disease each employee.
b. Commercial General Liability insurance with limits of at least $1,500,000 general aggregate,
$1,500,000 products - completed operations $1,500,000 personal and advertising injury,
$1,500,000 each occurrence $50,000 fire damage, and $5,000 medical expense any one
person. The policy shall be on an "occurrence" basis, shall include contractual liability
coverage and the City shall be named an additional insured.
c. Commercial Automobile Liability insurance covering all owned, non-owned and hired
automobiles with limits of at least$1,500,000 per accident.
d. Professional Liability. Professional (or "Errors & Omissions") Liability Insurance in the
amount of at least $1,500,000 Each Occurrence (or "wrongful Act" or equivalent) and, if
applicable, aggregate, covering Engineer's liability for negligent acts, errors or omissions in
the performance of professional services in connection with the work. Engineer's
Professional Liability Insurance may afford coverage on an occurrence basis or on a claims-
made basis. It is, however, acknowledged and agreed to by the Engineer that claims-made
coverage changes the liability insurance protection intended for the City. Therefore, Engineer
agrees that it will not seek or voluntarily accept any such change in its Professional Liability
Insurance coverage if such impairment of the protection for the City could result; and further,
that it will exercise its rights under any "extended Reporting Period" ("tail coverage") or
similar claims-made policy option if necessary or appropriate to avoiding impairment of such
protection. Engineer further agrees that it will, throughout the entire period of required
coverage and for an additional period of two (2) years following final acceptance of the
work, immediately: (a) advise the City of any intended or pending change in Professional
Liability insurers or in policy forms, and provide the City with all pertinent information that
the City may responsibly request to determine compliance with this subsection, and (b)
advise the City of any claims or threats of claims that might reasonably be expected to reduce
the amount of such insurance remaining available for the protection of the City.
Acceptance of the insurance by the City shall not relieve, limit or decrease the liability of the
Engineer. Any policy deductibles or retention shall be the responsibility of the Engineer. The
3-1
414887v42 CLL RS215-3
Engineer shall control any special or unusual hazards and be responsible for any damages that
result from those hazards. The City does not represent that the insurance requirements are
sufficient to protect the Engineer's interest or provide adequate coverage.
Evidence of coverage is to be provided on a City approved Certificate of Insurance. A thirty (30)
day written notice is required if the policy is canceled, not renewed or materially changed.
The Engineer shall require any of its subcontractors, if allowable under this contract, to comply
with these provisions. Acceptance of the insurance by the City shall not relieve, limit or
decrease the liability of the Engineer. Any policy deductibles or retention shall be the
responsibility of the Engineer. The Engineer shall control any special or unusual hazards and be
responsible for any damages that result from those hazards. The City does not represent that the
insurance requirements are sufficient to protect the Engineer's interest or provide adequate
coverage.
Evidence of coverage is to be provided on a City approved Certificate of Insurance. A thirty(30)
day written notice is required if the policy is canceled,not renewed or materially changed.
3-2
414887v-1-2 CLL RS215-3